Terms & Conditions

Welcome to our website. If you continue to browse and use this website, you are agreeing to comply with and be bound by the following terms and conditions of use. If you disagree with any part of these terms and conditions, please do not use our website.

The term ‘Hedgehog Development’ or ‘us’ or ‘we’ refers to the owner of the website. The term ‘you’ refers to the user or viewer of our website.

The use of this website is subject to the following terms of use:

  • The content of the pages of this website is for your general information and use only. It is subject to change without notice.
  • Neither we nor any third parties provide any warranty or guarantee as to the accuracy, timeliness, performance, completeness or suitability of the information and materials found or offered on this website for any particular purpose. You acknowledge that such information and materials may contain inaccuracies or errors and we expressly exclude liability for any such inaccuracies or errors to the fullest extent permitted by law.
  • Your use of any information or materials on this website is entirely at your own risk, for which we shall not be liable. It shall be your own responsibility to ensure that any products, services or information available through this website meet your specific requirements.
  • This website contains material which is owned by or licensed to us. This material includes, but is not limited to, the design, layout, look, appearance and graphics. Reproduction is prohibited other than in accordance with the copyright notice, which forms part of these terms and conditions.
  • All trademarks reproduced in this website, which are not the property of, or licensed to the operator, are acknowledged on the website.
  • Unauthorised use of this website may give rise to a claim for damages and/or be a criminal offence.
  • From time to time, this website may also include links to other websites. These links are provided for your convenience to provide further information. They do not signify that we endorse the website(s). We have no responsibility for the content of the linked website(s).
  • Your use of this website and any dispute arising out of such use of the website is subject to the laws of England, Northern Ireland, Scotland and Wales.

CONDITIONS OF APPOINTMENT FOR AN ARCHITECT

1 Definitions and interpretation1 Definitions and interpretation

1.1 Collaborate means to co-operate with and to provide to or receive from Other Persons, as and when requested, information reasonably necessary for performing work or services and, where the Architect considers itself competent to do so, to comment on such information.

Construction Acts means the Housing Grants Construction & Regeneration Act 1996 and the Local Democracy Economic Development and Construction Act 2009.

Letter of Appointment means the Letter of Appointment to which these Conditions are annexed.

Other Persons means any person, company or firm, other than the Architect or any sub-consultant of the Architect, including but not limited to consultants, contractors, sub-contractors, specialists, site inspectors or clerks of works, statutory bodies or undertakers, approving or adopting authorities, who have performed or will perform work or services in connection with the Project.

Project is defined in the Letter of Appointment.

Services means the services to be performed by the Architect specified in the schedule of Services annexed to the Letter of Appointment, which may be varied by agreement.

1.2 Where under this Agreement an action is required within a specified period of days from a specified date, that period commences immediately after that date. The period includes Saturdays and Sundays but excludes any day that is a public holiday.

1.3 The provisions of this Agreement continue to bind the Client and the Architect as long as necessary to give effect to their respective rights and obligations.

1.4 This Agreement is subject to the law and the parties submit to the exclusive jurisdiction of the courts of England and Wales or Northern Ireland or Scotland as specified in the Letter of Appointment.

2 Architect’s Services

2.1 The Architect shall exercise reasonable skill care and diligence in accordance with the normal standards of the Architect’s profession in performing the Services and discharging all the obligations under this clause 2.

2.2 The Architect shall:

2.2.1 perform the Services with due regard to the Client’s requirements;

2.2.2 advise on progress in the performance of the Services, of any information, decision or action required or of any issue that may affect the delivery, the cost or quality of the project;

2.2.3 a) act on behalf of the Client in the matters set out or implied in this Agreement;
b) if acting as Contract Administrator of a building contract, exercise impartial and independent judgement when dealing between the Client and the contractor;

2.2.4 collaborate with any Other Persons and, as applicable, shall integrate relevant information received from such persons into the Architect’s work;

2.2.5 make no material alteration to the Services or the approved design without the consent of the Client, except in an emergency.

2.3 The Architect shall have the right to publish photographs of the Project, and the Client shall give reasonable access to the Project for this purpose for two years after practical completion of the construction works.
3 Client’s responsibilities

3.1 The Client:

3.1.1 shall advise the Architect of the requirements and of any subsequent changes required;

3.1.2 shall provide, free of charge, the information in the client’s possession, or which is reasonably obtainable, and which is necessary for the proper and timely performance of the Services and the Architect shall be entitled to rely on such information;

3.1.3 shall give decisions and approvals necessary for the performance of the Services;

3.1.4 may issue reasonable instructions to the Architect.

3.2 The Client shall:

3.2.1 appoint and/or otherwise engage any Other Persons required to perform work or services under separate agreements and shall require them to collaborate with the Architect;

3.2.2 hold the contractor or contractors and not the Architect responsible for the proper carrying out and completion of construction works;

3.2.3 not deal with the contractor or contractors directly or interfere with the Architect’s duties or actions under the building contract.

3.3
The Client acknowledges that the Architect does not warrant:

3.2.1 that planning permission and other approvals from third parties will be granted at all or, if granted will be granted in accordance with any anticipated time-scale;

3.2.2 compliance with any programme and/or target cost for the building work which may need to be reviewed for, but not limited to:
a) variations requested by the Client;
b) variation in market prices;
c) delays caused by any Other Persons or any factor beyond the control of the Architect;
d) the discovery at any time of previously unknown conditions;

3.2.3 the competence, performance, work, services, products or solvency of any Other Persons.

4 Assignment

4.1 Neither the Architect nor the Client shall at any time assign the benefit of this Agreement or any rights arising under it without the prior written consent of the other, which consent shall not to be unreasonably withheld or delayed.

4.2 The Architect shall not sub-contract performance of any part of the Services without the prior consent of the Client, which consent shall not be unreasonably withheld or delayed.

5 Fees and expenses

5.1 The fees for performance of the Services and/or any additional services shall be calculated in accordance with this clause 5 and as specified in the Fees and Expenses Schedule, 2012 revision or in the Letter of Appointment.

5.2 The Basic Fee for performance of the Services shall be:

5.2.1 the specified percentage applied to the final cost of the building work; or

5.2.2 the separate percentages specified for each work stage applied to the approved cost of the building work at the end of the previous stage; or

5.2.3 the specified fixed lump sum or sums; or

5.2.4 time charges ascertained by multiplying the time reasonably spent in the performance of the Services by the specified hourly or daily rate for the relevant personnel. Time ‘reasonably spent’ includes the time spent in connection with performance of the Services in travelling from and returning to the Architect’s office; or

5.2.5 any combination of these; and/or

5.2.6 any other agreed method.

Where a percentage fee applies and until the actual cost of the building work is known, the percentages are applied to the current approved estimate of the cost of the building works or the contract sum. The cost shall exclude VAT, fees and any claims made by or against the contractor or contractors.

5.3 Lump sums, rates for time charges, mileage and printing shall be revised every 12 months in accordance with changes in the Consumer Price Index. Each 12-month period commences on the anniversary of the date on which the Architect commenced performance of the Services.

5.4 The Basic Fee shall be adjusted:

5.4.1 including due allowance for any loss and/or expense, if material changes are made to the Brief and/or the latest approved estimate of the cost of the building work and/or the programme and/ or the Services are varied by agreement;

5.4.2 where percentage fees in accordance with clauses 5.2.1 or 5.2.2 apply, to compensate for any reduction of the Construction Cost arising solely from deflationary market conditions not prevailing at the date of this Agreement.

5.5 If the Architect is involved in extra work or incurs extra expense for reasons beyond the Architect’s reasonable control, additional fees shall be calculated on a time basis in accordance with clause 5.2.4 where:

5.5.1 the cost of any work, installation or equipment, for which the Architect performs Services, is not included in the cost for the building work; and/or

5.5.2 the Architect is required to vary any item of work commenced or completed or to provide a new design after the Client has authorised development of an approved design: and/or

5.5.3 performance of the Services is delayed, disrupted or prolonged.

The Architect shall inform the Client on becoming aware that this clause 5.5 will apply. This clause 5.5 shall not apply where any change or extra work or expense arises from a breach of this Agreement by the Architect.

5.6 The Client shall reimburse the Architect for expenses in the manner specified in the Letter of Appointment.

5.7 The Architect shall maintain records of time spent on Services performed on a time basis and for any expenses and disbursements to be reimbursed at net cost. The Architect shall make such records available to the Client on reasonable request.

Payment notices

5.8 The Architect shall issue payment notices at the intervals specified in the Letter of Appointment.

Each notice shall comprise the Architect’s account setting out any accrued instalments of the fee and other amounts due, less any amounts previously paid and stating the basis of calculation of the amount specified which shall be ‘the notified sum’. The payment due date shall be the date of the Architect’s Payment Notice. Instalments of fees shall be calculated on the Architect’s reasonable estimate of the percentage of completion of the Services or stages or other services or any other specified method.

The Client shall pay the notified sum within 14 days of the date of issue of the relevant Notice (which shall be the ‘final date for payment’) unless:

a) The Architect has become insolvent (as defined in the Construction Acts at any time between the last date on which the Client could have issued the Notice under 5.9 and the final date for payment);
b) The Client issues a notice under 5.9.

Otherwise the amount due and payable shall be the notified sum. The Client shall not delay payment of any undisputed part of the notified sum.

The Architect shall submit the final account for fees and any other amounts due when the Architect reasonably considers the Services have been completed.

Notice of intention to pay less

5.9 If the Client intends to pay less than the notified sum the Client shall give a written notice to the Architect not later than five days before the final date for payment specifying the amount that the Client considers to be due on the date the Notice is served, the basis on which that sum is calculated and, if any sum is intended to be withheld, the ground for doing so or, if there is more than one ground, each ground and the amount attributable to it. The Client shall on or before the final date for payment make payment to the Architect of the amount if any specified in the written Notice.

If no such Notice is given the amount due and payable shall be the notified sum stated as due in the Architect’s account. The Client shall not delay payment of any undisputed part of the account. If the Client issues such a Notice and the matter is referred to an Adjudicator who decides that an additional sum greater than the amount stated in the notice of intention to pay less is due, the Client shall pay that sum within seven days of the date of the decision or the date which apart from the Notice would have been the final date for payment.

5.10 [number not used]

5.11 If performance of any or all of the Services and/or other obligations is suspended or ended, the Architect shall be entitled:

5.11.1 to payment of any part of the fee and other amounts properly due; together with

5.11.2 reimbursement of any loss and/damages caused to the Architect by reason of the suspension or the termination, except where the Architect is in material or persistent breach of the obligations under the Agreement.

5.12 In the event that any amounts are not paid when properly due, the payee shall be entitled to simple interest on such amounts until the date that payment is received at 8% per year over the dealing rate of the Bank of England Rate current at the date that payment becomes overdue, together with such costs reasonably incurred by the payee (including costs of time spent by principals, employees and advisors) in obtaining payment of any sums due under this Agreement.

5.13 The Client or the Architect shall pay to the other party who successfully pursues, resists or defends any claim or part of a claim brought by the other:

5.13.1 such costs reasonably incurred (including costs of time spent by principals, employees and advisors) where the matter is resolved by negotiation or mediation; or

5.13.2 such costs as may be determined by any tribunal to which the matter is referred.

5.14 In addition to the fees and expenses, the Client shall pay any Value Added Tax chargeable on the Architect’s fees and expenses.

6 Copyright licence

6.1 The Architect shall own all intellectual property rights including the copyright in the drawings and documents produced in performing the Services and generally asserts the Architect’s moral rights to be identified as the author of such work.

Providing that all fees and/or other amounts properly due are paid, the Client shall have a licence to copy and use the drawings and documents only for purposes related to construction of the Project or its subsequent use or sale but may not be used for reproduction of the design for any part of any extension of the Project or any other project.

Copying or use of the drawings and documents by an Other Person providing services to the Project shall be deemed to be permitted under a sub-licence granted by the Client, whether the drawings and documents were issued by the Client or on the Client’s behalf.

The Architect shall not be liable for any use of the drawings and documents other than for the purpose for which they were prepared.

No part of any design by the Architect may be registered by the Client without the written consent of the Architect.

7 Liability and insurance

7.1 No action or proceedings arising from the failure of the Architect to keep to this Agreement shall be commenced after the expiry of six years from the date of the last Services performed under this Agreement or, if earlier, practical completion of construction of the Project or such earlier date as prescribed by law.

7.2 In any such action or proceedings:

7.2.1 the Architect’s liability for loss or damage shall not exceed the amount of the Architect’s professional indemnity insurance available for the Project as specified in the Letter of Appointment providing the Architect has notified the insurers of the relevant claim or claims as required by the terms of such insurance.

7.2.2 No employee of the Architect or any agent of the Architect shall be personally liable to the Client for any negligence, default or any other liability whatsoever arising from performance of the Services.

7.3 [number not used]

7.4 The Architect shall maintain until at least the expiry of the period specified in clause 7.1 professional indemnity insurance with a limit of indemnity not less than the amount or amounts specified in the Letter of Appointment, provided such insurance continues to be offered on commercially reasonable terms to the Architect at the time when the insurance is taken out or renewed.

The Architect, when reasonably requested by the Client, shall produce for inspection a broker’s letter or certificate confirming that such insurance has been obtained and/or is being maintained.

7.5 Nothing in this Agreement confers or is intended to confer any right to enforce any of its terms on any person who is not a party to it, other than lawful assignees.
8 Suspension or termination

8.1 The Client may suspend or end performance of any or all of the Services and other obligations by giving at least seven days’ written notice and stating the reason for doing so.

The Architect may suspend or end performance of any or all of the Services and its obligations by giving at least seven days’ written notice and stating the ground or grounds on which it is intended to do so. Such ground or grounds include, but are not limited to, the Client’s failure to pay any fees or other amounts due, where applicable, by the final date for payment, unless the Client has given effective notice under clause 5.9 of the intention to pay less than the amount stated in an Architect’s account.

If the reason for a notice of suspension arises from a default:

8.1.1 which is remedied, the Architect shall resume performance of the Services and other obligations within a reasonable period; or

8.1.2 which is not remedied by the defaulting party, the Agreement will end by giving at least seven days’ further written notice.

Where Services are suspended by either party and not resumed within three months, the Architect has the right to treat performance of the Services affected as ended on giving at least seven days’ further written notice to the Client.

9 Dispute resolution

9.1 In the event of any dispute or difference arising under the Agreement, the parties may:

9.1.1 attempt to settle the matter by negotiation or mediation; or

9.1.2 start court proceedings to settle the dispute at any time; or

9.1.3 have disputes decided within 21 days by an adjudicator appointed under the RIBA Adjudication Scheme for Consumer Contracts.

9.2 If appointed, the Adjudicator may allocate between the parties the costs relating to the adjudication, including the fees and expenses of the adjudicator, in accordance with the provisions of clause 5.13.

10
Consumer’s right to cancel:

10.1 The consumer Client has the right to cancel this Agreement for any reason by delivering or sending (including by email) a cancellation notice to the Architect at any time within the period of seven days starting from the date when this Agreement was made.

10.2 The notice of cancellation is deemed to be served as soon as it is posted or sent to the Architect or in the case of an electronic communication on the day it is sent to the Architect.

10.3 If the Architect was instructed to perform any services before the Agreement was made or before the end of the seven day period and the instruction or instructions were confirmed in writing, the Architect shall be entitled to any fees and expenses properly due before the Architect receives the notice of cancellation.

10.4 The notice of cancellation is to be addressed to the Architect and state:

The Client <name> hereby gives notice that the RIBA Domestic Project Agreement, 2012 revision with the Architect <insert name> and signed [on our behalf] by <name of person(s) who [will sign] [signed]> on <date of signing> is cancelled.

Client signature(s):

Date

 
1.1 Collaborate means to co-operate with and to provide to or receive from Other Persons, as and when requested, information reasonably necessary for performing work or services and, where the Architect considers itself competent to do so, to comment on such information.

Construction Acts means the Housing Grants Construction & Regeneration Act 1996 and the Local Democracy Economic Development and Construction Act 2009.

 

Letter of Appointment means the Letter of Appointment to which these Conditions are annexed.

 

Other Persons means any person, company or firm, other than the Architect or any sub-consultant of the Architect, including but not limited to consultants, contractors, sub-contractors, specialists, site inspectors or clerks of works, statutory bodies or undertakers, approving or adopting authorities, who have performed or will perform work or services in connection  with the Project.

 

Project is defined in the Letter of Appointment.

 

Services means the services to be performed by the Architect specified in the schedule of Services annexed to the Letter of Appointment, which may be varied by agreement.

 
1.2 Where under this Agreement an action is required within a specified period of days from a specified date, that period commences immediately after that date. The period includes Saturdays and Sundays but excludes any day that is a public holiday.
 
1.3 The provisions of this Agreement continue to bind the Client and the Architect as long as necessary to give effect to their respective rights and obligations.
 
1.4 This Agreement is subject to the law and the parties submit to the exclusive jurisdiction of the courts of England and Wales or Northern Ireland or Scotland as specified in the Letter of Appointment.

 

2 Architect’s Services
 
2.1 The Architect shall exercise reasonable skill care and diligence in accordance with the normal standards of the Architect’s profession in performing the Services and discharging all the obligations under this clause 2.
 
2.2 The Architect shall:
 
2.2.1 perform the Services with due regard to the Client’s requirements;
2.2.2 advise on progress in the performance of the Services,  of any information, decision or action required or of any issue that may affect the delivery, the cost or quality of the project;
2.2.3 a)       act on behalf of the Client in the matters set out or implied in this Agreement;b)       if acting as Contract Administrator of a building contract, exercise impartial and independent judgement when dealing between the Client and the contractor;
2.2.4 collaborate with any Other Persons and, as applicable, shall integrate relevant information received from such persons into the Architect’s work;
2.2.5 make no material alteration to the Services or the approved design without the consent of the Client, except in an emergency.
2.3 The Architect shall have the right to publish photographs of the Project, and the Client shall give reasonable access to the Project for this purpose for two years after practical completion of the construction works.

 

 

3 Client’s responsibilities
 
3.1 The Client:
 
3.1.1 shall advise the Architect of the requirements and of any subsequent changes required;
3.1.2 shall provide, free of charge, the information in the client’s possession, or which is reasonably obtainable, and which is necessary for the proper and timely performance of the Services and the Architect shall be entitled to rely on such information;
3.1.3 shall give decisions and approvals necessary for the performance of the Services;
3.1.4 may issue reasonable instructions to the Architect.
3.2 The Client shall:
3.2.1 appoint and/or otherwise engage any Other Persons required to perform work or services under separate agreements and shall require them to collaborate with the Architect;
3.2.2 hold the contractor or contractors and not the Architect responsible for the proper carrying out and completion of construction works;
3.2.3 not deal with the contractor or contractors directly or interfere with the Architect’s duties or actions under the building contract.
3.3
The Client acknowledges that the Architect does not warrant:
3.2.1 that planning permission and other approvals from third parties will be granted at all or, if granted will be granted in accordance with any anticipated time-scale;
3.2.2 compliance with any programme and/or target cost for the building work which may need to be reviewed for, but not limited to:a)       variations requested by the Client;

b)       variation in market prices;

c)        delays caused by any Other Persons or any factor beyond the control of the Architect;

d)       the discovery at any time of previously unknown conditions;

3.2.3 the competence, performance, work, services, products or solvency of any Other Persons.

 

4 Assignment[1]
 
4.1 Neither the Architect nor the Client shall at any time assign the benefit of this Agreement or any rights arising under it without the prior written consent of the other, which consent shall not to be unreasonably withheld or delayed.
 
4.2 The Architect shall not sub-contract performance of any part of the Services without the prior consent of the Client, which consent shall not be unreasonably withheld or delayed.

 

5 Fees and expenses
 
5.1 The fees for performance of the Services and/or any additional services shall be calculated in accordance with this clause 5 and as specified in the Fees and Expenses Schedule, 2012 revision or in the Letter of Appointment.
5.2 The Basic Fee for performance of the Services shall be:
5.2.1 the specified percentage applied to the final cost of the building work; or
5.2.2 the separate percentages specified for each work stage applied to the approved cost of the building work at the end of the previous stage; or
5.2.3 the specified fixed lump sum or sums; or
5.2.4 time charges ascertained by multiplying the time reasonably spent in the performance of the Services by the specified hourly or daily rate for the relevant personnel. Time ‘reasonably spent’ includes the time spent in connection with performance of the Services in travelling from and returning to the Architect’s office; or
5.2.5 any combination of these; and/or
5.2.6 any other agreed method.
Where a percentage fee applies and until the actual cost of the building work is known, the percentages are applied to the current approved estimate of the cost of the building works or the contract sum. The cost shall exclude VAT, fees and any claims made by or against the contractor or contractors.
5.3 Lump sums, rates for time charges, mileage and printing shall be revised every 12 months in accordance with changes in the Consumer Price Index. Each 12-month period commences on the anniversary of the date on which the Architect commenced performance of the Services.
5.4 The Basic Fee shall be adjusted:
5.4.1 including due allowance for any loss and/or expense, if material changes are made to the Brief and/or the latest approved estimate of the cost of the building work and/or the programme and/ or the Services are varied by agreement;
5.4.2 where percentage fees in accordance with clauses 5.2.1 or 5.2.2 apply, to compensate for any reduction of the Construction Cost arising solely from deflationary market conditions not prevailing at the date of this Agreement.
5.5 If the Architect is involved in extra work or incurs extra expense for reasons beyond the Architect’s reasonable control, additional fees shall be calculated on a time basis in accordance with clause 5.2.4 where:
5.5.1 the cost of any work, installation or equipment, for which the Architect performs Services, is not included in the cost for the building work; and/or
5.5.2 the Architect is required to vary any item of work commenced or completed or to provide a new design after the Client has authorised development of an approved design: and/or
5.5.3 performance of the Services is delayed, disrupted or prolonged.
The Architect shall inform the Client on becoming aware that this clause 5.5 will apply. This clause 5.5 shall not apply where any change or extra work or expense arises from a breach of this Agreement by the Architect.
5.6 The Client shall reimburse the Architect for expenses in the manner specified in the Letter of Appointment.
5.7 The Architect shall maintain records of time spent on Services performed on a time basis and for any expenses and disbursements to be reimbursed at net cost. The Architect shall make such records available to the Client on reasonable request.
Payment notices
 
5.8[2] The Architect shall issue payment notices at the intervals specified in the Letter of Appointment.

Each notice shall comprise the Architect’s account setting out any accrued instalments of the fee and other amounts due, less any amounts previously paid and stating the basis of calculation of the amount specified which shall be ‘the notified sum’. The payment due date shall be the date of the Architect’s Payment Notice. Instalments of fees shall be calculated on the Architect’s reasonable estimate of the percentage of completion of the Services or stages or other services or any other specified method.

 

The Client shall pay the notified sum within 14 days of the date of issue of the relevant Notice (which shall be the ‘final date for payment’) unless:

 

a)       The Architect has become insolvent (as defined in the Construction Acts at any time between the last date on which the Client could have issued the Notice under 5.9 and the final date for payment);

b)       The Client issues a notice under 5.9.

 

Otherwise the amount due and payable shall be the notified sum. The Client shall not delay payment of any undisputed part of the notified sum.

 

The Architect shall submit the final account for fees and any other amounts due when the Architect reasonably considers the Services have been completed.

Notice of intention to pay less
5.9 If the Client intends to pay less than the notified sum the Client shall give a written notice to the Architect not later than five days before the final date for payment specifying the amount that the Client considers to be due on the date the Notice is served, the basis on which that sum is calculated and, if any sum is intended to be withheld, the ground for doing so or, if there is more than one ground, each ground and the amount attributable to it. The Client shall on or before the final date for payment make payment to the Architect of the amount if any specified in the written Notice.

If no such Notice is given the amount due and payable shall be the notified sum stated as due in the Architect’s account. The Client shall not delay payment of any undisputed part of the account. If the Client issues such a Notice and the matter is referred to an Adjudicator who decides that an additional sum greater than the amount stated in the notice of intention to pay less is due, the Client shall pay that sum within seven days of the date of the decision or the date which apart from the Notice would have been the final date for payment.

5.10 [number not used]
5.11 If performance of any or all of the Services and/or other obligations is suspended or ended, the Architect shall be entitled:
5.11.1 to payment of any part of the fee and other amounts properly due; together with
5.11.2 reimbursement of any loss and/damages caused to the Architect by reason of the suspension or the termination, except where the Architect is in material or persistent breach of the obligations under the Agreement.
5.12 In the event that any amounts are not paid when properly due, the payee shall be entitled to simple interest on such amounts until the date that payment is received at 8% per year over the dealing rate of the Bank of England Rate current at the date that payment becomes overdue, together with such costs reasonably incurred by the payee (including costs of time spent by principals, employees and advisors) in obtaining payment of any sums due under this Agreement.
5.13 The Client or the Architect shall pay to the other party who successfully pursues, resists or defends any claim or part of a claim brought by the other:
5.13.1 such costs reasonably incurred (including costs of time spent by principals, employees and advisors) where the matter is resolved by negotiation or mediation; or
5.13.2 such costs as may be determined by any tribunal to which the matter is referred.
5.14 In addition to the fees and expenses, the Client shall pay any Value Added Tax chargeable on the Architect’s fees and expenses.

 

6 Copyright licence
 
6.1 The Architect shall own all intellectual property rights including the copyright in the drawings and documents produced in performing the Services and generally asserts the Architect’s moral rights to be identified as the author of such work.

Providing that all fees and/or other amounts properly due are paid, the Client shall have a licence to copy and use the drawings and documents only for purposes related to construction of the Project or its subsequent use or sale but may not be used for reproduction of the design for any part of any extension of the Project or any other project.

 

Copying or use of the drawings and documents by an Other Person providing services to the Project shall be deemed to be permitted under a sub-licence granted by the Client, whether the drawings and documents were issued by the Client or on the Client’s behalf.

 

The Architect shall not be liable for any use of the drawings and documents other than for the purpose for which they were prepared.

 

No part of any design by the Architect may be registered[3] by the Client without the written consent of the Architect.

 

7 Liability and insurance
 
7.1 No action or proceedings arising from the failure of the Architect to keep to this Agreement shall be commenced after the expiry of six years from the date of the last Services performed under this Agreement or, if earlier, practical completion of construction of the Project or such earlier date as prescribed by law.
 
7.2 In any such action or proceedings:
 
7.2.1 the Architect’s liability for loss or damage shall not exceed the amount of the Architect’s professional indemnity insurance available for the Project as specified in the Letter of Appointment providing the Architect has notified the insurers of the relevant claim or claims as required by the terms of such insurance.
7.2.2 No employee of the Architect or any agent of the Architect shall be personally liable to the Client for any negligence, default or any other liability whatsoever arising from performance of the Services.
7.3 [number not used]
7.4 The Architect shall maintain until at least the expiry of the period specified in clause 7.1 professional indemnity insurance with a limit of indemnity not less than the amount or amounts specified in the Letter of Appointment, provided such insurance continues to be offered on commercially reasonable terms to the Architect at the time when the insurance is taken out or renewed.

The Architect, when reasonably requested by the Client, shall produce for inspection a broker’s letter or certificate confirming that such insurance has been obtained and/or is being maintained.

7.5 Nothing in this Agreement confers or is intended to confer any right to enforce any of its terms on any person who is not a party to it, other than lawful assignees.

 

 

8 Suspension or termination
 
8.1 The Client may suspend or end performance of any or all of the Services and other obligations by giving at least seven days’ written notice and stating the reason for doing so.

The Architect may suspend or end performance of any or all of the Services and its obligations by giving at least seven days’ written notice and stating the ground or grounds on which it is intended to do so. Such ground or grounds include, but are not limited to, the Client’s failure to pay any fees or other amounts due, where applicable, by the final date for payment, unless the Client has given effective notice under clause 5.9 of the intention to pay less than the amount stated in an Architect’s account.

 

If the reason for a notice of suspension arises from a default:

 
8.1.1 which is remedied, the Architect shall resume performance of the Services and other obligations within a reasonable period; or
8.1.2 which is not remedied by the defaulting party, the Agreement will end by giving at least seven days’ further written notice.
Where Services are suspended by either party and not resumed within three months, the Architect has the right to treat performance of the Services affected as ended on giving at least seven days’ further written notice to the Client.

 

9 Dispute resolution[4]
 
9.1 In the event of any dispute or difference arising under the Agreement, the parties may:
 
9.1.1 attempt to settle the matter by negotiation or mediation; or
9.1.2 start court proceedings to settle the dispute at any time; or
9.1.3 have disputes decided within 21 days by an adjudicator appointed under the RIBA Adjudication Scheme for Consumer Contracts.[5]
9.2 If appointed, the Adjudicator may allocate between the parties the costs relating to the adjudication, including the fees and expenses of the adjudicator, in accordance with the provisions of clause 5.13.

 

 

 

 10  Consumer’s right to cancel:
 
10.1 The consumer Client has the right to cancel this Agreement for any reason by delivering or sending (including by email) a cancellation notice to the Architect at any time within the period of seven days starting from the date when this Agreement was made.
 
10.2 The notice of cancellation is deemed to be served as soon as it is posted or sent to the Architect or in the case of an electronic communication on the day it is sent to the Architect.
10.3 If the Architect was instructed to perform any services before the Agreement was made or before the end of the seven day period and the instruction or instructions were confirmed in writing, the Architect shall be entitled to any fees and expenses properly due before the Architect receives the notice of cancellation.
10.4 The notice of cancellation is to be addressed to the Architect and state:
The Client <name> hereby gives notice that the RIBA Domestic Project Agreement, 2012 revision with the Architect <insert name> and signed [on our behalf] by <name of person(s) who [will sign] [signed]> on <date of signing> is cancelled.
Client signature(s):
Date

 


[1] Assignation in Scotland.

[2] In the event of non-payment of any amount properly due to the Architect under this Agreement, the Architect is entitled to interest on the unpaid amounts under the provisions of clause 5.9, may suspend use of the licence under the provisions of clause 6, may suspend or terminate performance of the Services and other obligations under the provisions of clause 8, or may commence dispute resolution procedures and/or debt recovery procedures.

 

[3] Under the Registered Designs Regulations 2001.

[4] The Architect is expected to operate in-house procedures to promptly handle complaints and disputes relating to specific project or performance matters.

[5] Only the consumer can make a decision to use arbitration.